Terms & Conditions

1. Introduction

Welcome to Aetreo Technologies ("Aetreo", "Company", "we", "our", or "us").

These Terms & Conditions govern your use of our website, products, applications, services, and any related content provided through www.aetreo.net.

By accessing or using our website or services, you agree to be bound by these Terms & Conditions. If you do not agree with these terms, please discontinue use of our website and services.

2. Company Information

Aetreo Technologies provides digital consulting, software development, mobile application development, UI/UX design, cloud services, DevOps solutions, AI-powered applications, and related technology services.

3. Acceptance of Terms

By using our website, you confirm that:

• You are at least 18 years old or legally authorized to enter into agreements.
• You have the authority to represent any organization on whose behalf you use our services.
• You will comply with all applicable laws and regulations.

4. Use of Website

You agree to use our website only for lawful purposes.

You shall not:

• Attempt unauthorized access to systems or data
• Introduce malicious code or viruses
• Disrupt website functionality
• Engage in fraudulent activities
• Use the website for illegal purposes
• Copy or distribute content without authorization

We reserve the right to suspend or terminate access for violations of these terms.

5. Intellectual Property Rights

Unless otherwise stated, all content on this website is owned by or licensed to Aetreo Technologies, including:

• Logos
• Branding
• Graphics
• Website design
• Software code
• Documentation
• Marketing materials
• Text content

All intellectual property rights are reserved.

You may not reproduce, modify, distribute, publish, or commercially exploit any content without prior written permission.

6. Client Services

Specific project engagements may be governed by separate agreements including:

• Master Service Agreements (MSA)
• Statements of Work (SOW)
• Service Contracts
• Non-Disclosure Agreements (NDA)
• Project Proposals

Where such agreements exist, they shall take precedence over these Terms & Conditions for the relevant services.

7. Quotations and Proposals

Any quotation, estimate, or proposal provided by Aetreo:

• Is valid only for the period stated therein
• May be subject to change before acceptance
• Does not constitute a binding agreement until formally accepted

Project scope changes may result in revised pricing and timelines.

8. Payment Terms

Unless otherwise agreed in writing:

• Payments shall be made according to agreed milestones.
• Invoices are payable within the specified due date.
• Delayed payments may result in suspension of services.
• Applicable taxes shall be charged as required by law.

Aetreo reserves the right to withhold deliverables until outstanding payments are settled.

9. Project Delivery

Project timelines are estimates unless explicitly stated otherwise.

Delivery may be affected by:

• Client approval delays
• Changes in scope
• Third-party dependencies
• Force majeure events
• Delayed client inputs

Aetreo shall not be liable for delays arising from factors beyond its reasonable control.

10. Client Responsibilities

Clients agree to:

• Provide accurate information
• Supply required content and materials
• Review deliverables in a timely manner
• Provide approvals and feedback promptly
• Maintain access credentials securely

Project delays caused by client inaction may impact delivery schedules.

11. Confidentiality

Both parties agree to maintain confidentiality regarding:

• Business information
• Trade secrets
• Technical documentation
• Financial information
• Proprietary processes

Confidential information shall not be disclosed except as required by law.

12. Third-Party Services

Our solutions may integrate with third-party services including:

• Cloud providers
• Payment gateways
• Analytics platforms
• APIs
• Social media platforms

Aetreo is not responsible for:

• Third-party outages
• Service interruptions
• Policy changes
• Security incidents occurring within third-party platforms

13. Software Ownership

14. Warranty Disclaimer

Services and website content are provided on an "as-is" and "as-available" basis.

Aetreo does not guarantee:

• Uninterrupted service availability
• Error-free operation
• Complete security against cyber threats
• Compatibility with all systems or devices

To the fullest extent permitted by law, all warranties are disclaimed.

15. Limitation of Liability

To the maximum extent permitted by law, Aetreo shall not be liable for:

• Indirect damages
• Consequential damages
• Loss of profits
• Loss of business opportunities
• Data loss
• Reputational damage

Total liability shall not exceed the amount paid by the client for the specific services giving rise to the claim.

16. Indemnification

You agree to indemnify and hold harmless Aetreo Technologies, its directors, employees, contractors, and affiliates from claims arising out of:

• Violation of these Terms
• Misuse of services
• Intellectual property infringement
• Illegal activities

17. Data Protection and Privacy

Your use of our website and services is also governed by our Privacy Policy. Please review our Privacy Policy for information regarding data collection, processing, and security.

18. Force Majeure

Aetreo shall not be responsible for delays or failures caused by events beyond reasonable control, including:

• Natural disasters
• Government actions
• Internet outages
• Cyberattacks
• Labor disputes
• Pandemics
• Utility failures

19. Termination

We reserve the right to:

• Suspend access
• Terminate services
• Refuse future service

for violations of these Terms or applicable laws.

Clients may terminate service agreements in accordance with contract provisions.

20. Governing Law

These Terms & Conditions shall be governed by and construed in accordance with the laws of India.

Any disputes arising under these Terms shall be subject to the exclusive jurisdiction of the courts located in Jodhpur, Rajasthan, India.

21. Amendments

Aetreo may update these Terms & Conditions from time to time.

Updated versions will be posted on our website with a revised effective date. Continued use of our website or services constitutes acceptance of any revisions.

22. Contact Information

For questions regarding these Terms & Conditions, please contact: